首页 > 合同协议 > 合同书 > 购销合同 > 广告礼品购销合同(实用三篇)正文

《广告礼品购销合同(实用三篇)》

时间:

广告礼品购销合同(通用3篇)

广告礼品购销合同 篇1

甲方:______________ 乙方:______________

经甲、乙双方协商,甲方向乙方定购以下商品。经双方友好协商,订制本合同条款如下:

一:品名、数量、价款。

品名:______________ 规格:______________

数量:______________ 单价:______________

金额:______________ 备注:______________

合 计 币:__________________

三:按甲方要求,在产品上印刷LOGO方式为:____________

四:制作周期______天。

五:结算方式及期限:本合同签定之日甲方应向乙方支付该合同总金额的______%定金,金额为_______元人民币,剩余货款甲方应在乙方货到之日,验收合格后一次付清全款。

六:交货方式:______________

交货时间:______________

交货地点:______________ 。

七:合同生效后,乙方收取甲方定金后开始生产,如甲方中途改动设计,乙方有权推迟交货期。

八:本合同一式两份,双方签字盖章方可生效,上述各项条款未尽事宜一律根据《中华人民共和国民法典》中相关规定执行。

九:其他约定事项:

甲方 单位:______________

地址:______________ 电话:______________

传真:______________ 网址:______________

邮箱:______________ 委托人:______________

执照号码:______________ 税务登记号码:______________

乙方单位:______________

地址:______________ 电话:______________

传真:______________ 网址:______________

邮箱:______________ 委托人:______________

执照号码:______________ 税务登记号码:______________

广告礼品购销合同 篇2

甲方:______________

乙方:______________

经甲、乙双方协商,甲方向乙方定购以下商品。经双方友好协商,订制本合同条款如下:

一、品名、数量、价款。

品名:______________规格:______________

数量:______________单价:______________

金额:______________备注:______________

合计币:__________________

二、按甲方要求,在产品上印刷LOGO方式为:____________。

三、制作周期______天。

四、结算方式及期限:本合同签定之日甲方应向乙方支付该合同总金额的______%定金,金额为_______元人民币,剩余货款甲方应在乙方货到之日,验收合格后一次付清全款。

五、交货方式:______________;交货时间:______________;交货地点:______________ 。

六、合同生效后,乙方收取甲方定金后开始生产,如甲方中途改动设计,乙方有权推迟交货期。

七、本合同一式两份,双方签字盖章方可生效,上述各项条款未尽事宜一律根据《中华人民共和国民法典》中相关规定执行。

甲方单位:______________

地址:______________电话:______________

传真:______________ 网址:______________

邮箱:______________委托人:______________

执照号码:______________税务登记号码:______________

乙方单位:______________

地址:______________电话:______________

传真:______________ 网址:______________

邮箱:______________委托人:______________

执照号码:______________税务登记号码:______________

广告礼品购销合同 篇3

Address:

Telephone:

Party B: Address:

Telephone:

According to the provisions of the contract law of the People's Republic of China and the relevant laws and regulations, Party B accepts the entrustment of the first party and entrustment with the two parties through consultation.

First, entrustment:

Two, the way of payment:

1, Party A shall pay 40% of the total cost of the contract, namely ____ yuan (RMB) to Party B, Party B received the money after the start of design.

2. Party B shall provide complete design draft. After confirmation by Party A, the total amount of the total cost shall be paid.

Three. Design time:

1, Party B shall provide complete design draft in __ working days.

2, Party B shall complete the design work of party a company commissioned in _____ years __ month __ day (delay time by party a reason, work time should be postponed).

Four. The responsibilities and obligations of the two parties:

1, Party B shall, according to the requirements of Party A to finish the related work on time.

2, Party A has the responsibility to fully cooperate with Party B to carry out the work stipulated in this contract and provide relevant information according to the needs of Party B. Party A is responsible for the consequences caused by Party A's delay in the required information.

3. Party A shall provide complete design information before the start of the design, due to Party A's provision of incomplete information and changes in content.

For structural changes, Party A shall pay the corresponding cost of design changes.

4. After Party B receives the complete design information of Party A, it is designed to facilitate the determination of the style of Party A, and Party B begins to design the first draft after the style is determined.

5, Party A has the right to put forward amendments to the works designed by Party B. The first draft Party A can make a structural modification. After the first draft is determined, the structural modifications should be made. Party A shall pay the corresponding cost separately.

6. The consequences of the delay due to the amendment of Party A shall be borne by Party A.

7, due to the loss caused by post production by Party A alone, the loss caused by problems in the design of the product is borne by Party B. The legal liability caused by copyright, for the economic disputes shall be borne by Party a..

8. During the course of the project, Party B is attached to the brand of Party A and shall not sign any form of cooperation agreement with the customer in the identity of Party B.

Five. The agreement on intellectual property rights:

1, Party B has the copyright of the works completed by the design. After the settlement of all the fees designed by Party A, Party B may transfer the copyright of the works to Party A.

2. Before Party A has not paid all the cost of the design, the copyright of the works designed by Party B shall be attributed to Party B, and Party A does not have any right to the work.

3. Party A shall have the right to investigate the legal liability of Party A if it uses or amends the works designed by Party B before the payment is not paid.

Six. Liability for breach of contract:

1, Party A terminates the contract before the completion of the first draft of the design work. The prepaid expenses have no right to request the return. If a party terminates the contract after the completion of the first draft of Party B's work, it shall pay the full design fee.

2. If Party B terminates the contract without proper reasons, the fees charged shall be returned to Party A.

Seven, if a party or a party has a dispute over the performance of this contract, it shall be settled amicable through negotiation. If either party fails to negotiate, any Party A and B can submit it to the Beijing Arbitration Commission for arbitration.

Eight, the contract is effective from the date of signature by Gai Zhang and both parties. The contract is two copies in one form. Each party has one contract signed by the other party (Gai Zhang), which has the same legal effect.

Nine. If there is no matter in this contract, the two parties shall jointly discuss and supplement the contract. The contents of the supplement and modification are equally valid to this contract.

Party A: Party B:

(signature seal) (signature seal)

Date: Date:

中文版

地址:

电话:

乙方:地址:

电话:

依据《中华人民共和国合同法》和有关法规的规定,乙方接受甲方的委托,就委托设计事项,双方经协商一致,签订本合同,信守执行:

一、委托事项:

二、付款方式:

1、甲方需在合同签订之时支付总费用的40% ,即____元(人民币)给乙方,乙方收到甲方的款项后开始设计。

2、乙方提供完整的设计稿,甲方确认后,应当即付清总费用的全部余款。

三、设计时间:

1、乙方需在__个工作日内提供比较完整的设计稿。

2、乙方需在_____年__月__日完成甲方公司委托的设计工作 (由甲方原因耽误的时间,完稿时间应顺延)。

四、双方的责任与义务:

1、乙方应按甲方要求按质按量按时完成相关设计工作。

2、甲方有责任全力配合乙方开展本合同所规定的工作,并根据乙方需要提供相关资料。由于甲方提供所需资料延误时间造成的后果,由甲方承担。

3、甲方应在设计开始前提供完整的设计资料,由于甲方提供资料不完整、内容改动而造成的设

计结构改动,甲方须另行支付相应的设计改动费用。

4、乙方收到甲方的完整设计资料后进行部分小样设计以方便甲方确定风格,风格确定后乙方开始进行初稿设计。

5、甲方有权对乙方所设计的作品提出修改意见,初稿甲方可提出一次结构上的修改,初稿确定后的结构修改,甲方须另行支付相应费用。

6、因甲方修改,延误时间造成的后果,由甲方承担。

7、由于后期制作造成的损失由甲方独自承担,由于制作物设计出现问题造成的损失由乙方承担。  因版权、文责所引发的法律责任,经济纠纷由甲方承担。

8、设计项目期间乙方挂靠于甲方品牌之中,不得以乙方身份单独与客户签订任何形式的合作协议

五、知识产权约定:

1、乙方对设计完成的作品享有著作权。甲方将委托设计的所有费用结算完毕后,乙方可将作品著作权转让给甲方。

2、甲方在未付清所有委托设计费用之前,乙方设计的作品著作权归乙方,甲方对该作品不享有任何权利。

3、甲方在余款未付清之前擅自使用或者修改使用乙方设计的作品而导致的侵权,乙方有权追究其法律责任。

六、违约责任:

1、甲方在设计作品初稿完成前终止合同,其预付的费用无权要求退回;甲方在乙方作品初稿完成后终止合同的,应当支付全额的设计费用。

2、乙方如无正当理由提前终止合同,所收取的费用应当全部退回给甲方。

七、甲乙双方如因履行本合同发生纠纷,应当友好协商解决,协商不成的,甲乙双方任何一方均可向北京仲裁委员会提请仲裁解决。

八、本合同自甲乙双方签字盖章之日起生效,本合同一式两份,双方各持对方签字(盖章)合同一份,具有同等的法律效力。

九、本合同如有未尽事宜,由甲乙双方共同讨论补充或修改。补充和修改的内容与本合同具有同等效力。

甲方:  乙方:

(签字盖章)  (签字盖章)